Acceptance of Terms

By using our website and services, you agree to be bound by these Terms and Conditions.

Use of Our Website

You agree to use our website for lawful purposes only. You may not use our website to engage in any illegal or harmful activities.

Intellectual Property

All content on our website, including text, images, and logos, is protected by copyright laws. You may not use our content without our prior written consent.

Product Information

We make every effort to ensure that the product information on our website is accurate and up-to-date. However, we cannot guarantee that all information is error-free.

• Governing Law and Jurisdiction Clauses

  The terms and conditions contained herein regarding the provision of services shall be governed and interpreted in accordance with the laws of India, and any dispute arising therefrom shall be submitted to the exclusive jurisdiction of the courts at Hyderabad, India.

• Quotation Terms

  1. Validity

      Quotations are valid for 90 days from the issuance date. After this period, Azven Group reserves the right to amend or revise the terms and prices of the quote.

  2. Minimum Order Value

      The minimum order value to proceed with Azven Group services is ₹1.5 Lakhs Net (Modular).

  3. Discounts

      Discounts are capped at a maximum allowable limit. Any reduction in project value will proportionally decrease the applicable discount percentage

• Service Overview

  Azven Group Plywood Kitchens and Wardrobes provide the following services only:
  1. 1. Design consultation with experts at Azven Group Experience centers
  2. 2. Manufacturing and fabricating Modular Kitchens, Wardrobes, and TV Units.
  3. 3. Installation of Modular products at your site- apartment, villa, house, etc.,
  4. 4. Exclusions: Additional Services: Floor guard and Deep cleaning services are not included in the standard offering and will incur additional charges upon request.
  Scope Limitations: Any items or services not explicitly mentioned in the quotation are excluded from the agreement.

• Payment Term

  1. General Payment Conditions:

     All payments made at each stage of the project are strictly non-refundable, non-transferable, and non-redeemable under any circumstances. Your initial payment confirms your acceptance of Azven Group’s terms and conditions and your consent to proceed with our services.

  2. Payment Procedure for Services (Modular):

     The finalized and approved quotation for Azven Group will be considered as the total payable price. The price shall be payable upon reaching the following milestones:

     STAGE	PAYMENT MILESTONE
     Order Book	10%
     Design Sign Off	40%
     Before Material Dispatch	50%

     Any payment delays will affect the project timeline.

  3. Project DeScope:

     In the event of a project scope reduction during the design phase, a 10% deduction of the total Order Book (Signup) value will apply. This amount covers site survey costs, design fees, and other associated overheads.

  4. Payment Methods:

     All payments shall be made via cheque, demand draft, or bank transfer (NEFT/RTGS). If payments fall below ₹10,000, cash payment mode will be accepted.

• Design Stage Process

  SNO.	STAGE	SUBSTAGE	DETAILS	TIMELINE
  1.	Site Measurements	Initial measurements	Conducted after the Order Book to align the site measurement team	3-5 Working Days
  2.	Design Phase	Design finalization, material selection	-Project Value < ₹8 Lakhs: 2-3 weeks (max 2 iterations) -Project Value ₹8-15 Lakhs:3-4 weeks (max 3 iterations) -Applicable only for Modular Projects valued < ₹15 Lakhs -Each correction typically takes 3-5 working days, depending on the scope and changes	3-4 Weeks*
  3.	Design Approval	Design Approval	No changes are allowed after the Sign-Off Document preparation starts.
  		Final measurements	Conducted after Design approval to align the Operations team for final measurements.	3-5 Working Days
  4.	Design Sign Off	Corrections, Signoff & Payment	-Corrections made according to site conditions -No modifications accepted after Design Sign-Off as the production phase begins.	3-5 Working Days

  * Timeless are indicative and subject to change based on design iterations, client availability, design feasibility approvals, and client approvals.

• Design Signoff

  Upon final Design Signoff, no modifications can be accommodated as production phase will commence immediately. All drawings must be reviewed carefully and confirmed before sign-off. – Images shown in the Design signoff are only for reference. Please refer to the physical samples for actual Color/ Finish/ Size.

• Cancellation Terms

  1. Neither of us may terminate this agreement. However, Azven Group may delay or cease to provide the services in case the price payable remains unpaid or is delayed; in which case, Azven Group shall have no obligation to refund the amounts already paid by you.
  2. After agreeing to these terms and conditions, in case you seek to not avail of the services, you will forfeit all the amounts already paid by you to Azven Group and also be liable to pay the balance of the price agreed to be paid to Azven Group, as due compensation for the losses that will be suffered by Azven Group in such an eventuality and not as a penalty.